690 Phil. 640
SERENO, J.:
On October 26, 2000, the petitioner Julieta Bernardo (Ms. Bernardo), offered to purchase a condominium unit described as Unit E with an area of 37 square meters of the Paseo Parkview Suites Tower II project of the developer Megaworld Corporation (Megaworld) located at Sedeño corner Valero Streets, Salcedo Village, Makati City. The said project was to be constructed on the lots covered by Transfer Certificates of Title Nos. 160210, 160211 and 160212, which are located at Makati City. The purchase price of the unit is P2,935,785.00 and Ms. Bernardo paid .19,571.90 as her reservation deposit, thus, a Request for Reservation [and Offer to Purchase] was completed by Ms. Bernardo and the same was assented to by Megaworld. Subsequently, a Contract to Buy and Sell dated November 22, 2000 was furnished to Ms. Bernardo. The said contract stipulated therein that the condominium unit would be delivered not later than July 31, 2003 with an additional grace period of six (6) months. As of October 22, 2003, Ms. Bernardo was able to pay the amount of P901,728.40. On April 15, 2004, Megaworld sent a letter to Ms. Bernardo regarding the transmittal of the Deed of Absolute Sale for her to affix her signatures thereto and for her to pay taxes and other fees so that Megaworld could start with the processing of her bank loan. Attached with the letter is a schedule of expenses needed in the transfer of the certificate of title in favor of Ms. Bernardo. The taxes and other fees to be paid by Ms. Bernardo amounted to P93,318.13. The conflict arose when Megaworld sent a letter dated August 9, 2004 to Ms. Bernardo as a final notice of cancellation or rescission of the Request for Reservation because of the latter’s alleged failure to make the necessary payments.
Consequently, Ms. Bernardo inquired with the Housing and Land Use Regulatory Board (HLURB) on the records of the project and she learned that the Certificate of Registration and the License to Sell for the project Paseo Parkview Tower 2 were only issued by HLURB on June 7, 2001. Hence, Ms. Bernardo, represented by Romeo Ruiz, filed a complaint on August 12, 2004 before the City Prosecutor of Makati City against the respondents for violations of Sections 5, 17 and 20 of Presidential Decree No. 957, otherwise known as “Regulating the Sale of Subdivision Lots and Condominiums, Providing Penalties for Violations Thereof” and the Revised Implementing Rules and Regulations of P.D. 957 and Estafa through False Pretenses and Fraudulent Acts before the Office of the City Prosecutor. Ms. Bernardo alleged that, since the Reservation Agreement (or Request for Reservation) was executed between her and Megaworld on October 26, 2000, the respondents should have caused the annotation of the same within 180 [days] therefrom or until April 24, 2001, that no annotation on the certificates of title was done when she verified the same, that Megaworld was never able to deliver the condominium unit on the stipulated deadline, which was [] on December 2003 and that, by such acts and omissions, Megaworld and the project owner, Sedeño Manor, violated the provisions of P.D. 957 to her prejudice.
In a Joint Counter-Affidavit filed by some of the respondents herein, they averred that Megaworld applied for a Certificate of Registration and License to Sell for the project as early as July 1, 1998, that subsequently, a License to Sell was issued by the HLURB but only for the Paseo Parkview Suites Phase 1 due to the modifications in the Paseo Parkview Suites Tower 2, that there was no intent on the part of Megaworld to defraud Ms. Bernardo because, when the latter requested for reservation, it has applied for the registration of the project and to have license to sell the units on the said project, that when HLURB issued the corresponding certificate and license for the Phase 1, it is understood that Megaworld is a dealer of good refute [sic] and is financially stable, that the subsequent issuance of the certificate of registration and license to sell on June 7, 2001 for the Tower 2 proved that Megaworld had good standing in pursuing the project, that subsequent certifications for the Tower 2 were issued before its completion, that Ms. Bernardo was not in good faith in filing the complaint against the respondents as she had defaulted in the payment of her obligations and also failed to settle the balance of P2,016,145.71 with interest and penalty charges amounting to P181,453.11 and that no damage was incurred by Ms. Bernardo since the Contract to Buy and Sell was never executed.
In a Resolution dated December 29, 2004, the City Prosecutor dismissed the complaint of Ms. Bernardo. Consequently, she filed a petition for review with the Secretary of Justice. Her petition was granted by the Secretary of Justice, hence, it ordered the filing of the corresponding Informations for violations of Sections 5, 17 and 20 of P.D. No. 957. The said Informations were filed in RTC, Branch 62 in Makati City. Due to the voluntary inhibition of the presiding judge of the said court, the case was re-assigned to RTC, Branch 150.
Aggrieved, the respondents moved for the reconsideration of the filing of the Informations against them. This time, the Secretary of Justice ruled in their favor and granted their motion in a Resolution dated November 17, 2005. Hence, pursuant to the Resolution, the Secretary of Justice ordered the City Prosecutor to move for the withdrawal of the Informations filed before the [trial] court. Acting on the motion of the City Prosecutor, the public respondent court issued the assailed Order dated June 29, 2006. The pertinent portion of the said order is quoted as follows:“As correctly ruled by the Secretary of Justice, it is overly simplistic to consider respondents as having violated Section 5 of P.D. 957 requiring licenses to be secured for each phase of the project. Under Title I of P.D. 957 a condominium project shall mean the entire parcel of real property divided or to be divided primarily for residential purposes into condominium units including all structures thereon. Clearly, the requirement of securing a license for each phase refers to a subdivision project not a condominium project. There is therefore doubt as to whether or not Section 5 of P.D. 957 can be a basis for prosecuting the respondents. x x x.”
“Respondents cannot also be indicted for violation of Section 17 of P.D. 957 for failure to register the Contract to Buy and Sell with the Registry of Deeds of Makati City because they did not have in their possession said document. Their inability to register the same was justified. x x x.”
“Section 20 of P.D. 957 should not also [be] applied mechanically against the respondents. Under the Contract to Buy and Sell, Megaworld is mandated to complete the project by July 23, 2003 with a grace period of six (6) months barring delays due to manmade or natural causes. Upon its completion, Megaworld shall notify the complainant of such fact, which shall constitute constructive delivery of subject condominium unit. Under the facts obtaining, respondents had no obligation to notify the complainant of the completion and availability of the unit for occupancy due to complainant’s failure to pay in full the purchase price of the unit. In fact, Megaworld prepared a notice to cancel/rescind and forfeit the Contract to Buy and Sell due to complainant’s default. Following this theory, the non-completion of Phase II of the condominium project cannot be made the basis of criminal prosecution under the aforecited section of P.D. 957.”
Consequently, Ms. Bernardo filed a motion for reconsideration but the same was denied by the [trial] court in [an Order] dated September 8, 2006. (Citations omitted)
[The court] may therefore grant or deny at its option a motion to dismiss or to withdraw the information based on its own assessment of the records of the preliminary investigation submitted to it, in the faithful exercise of judicial discretion and prerogative, and not out of subservience to the prosecutor. While it is imperative on the part of a trial judge to state his/her assessment and reasons in resolving the motion before him/her, he/she need not state with specificity or make a lengthy exposition of the factual and legal foundation relied upon to arrive at the decision. (Emphasis supplied and citations omitted)
[Probable cause] is such a state of facts in the mind of the prosecutor as would lead a person of ordinary caution and prudence to believe or entertain an honest or strong suspicion that a thing is so. The term does not mean “actual or positive cause”; nor does it import absolute certainty. It is merely based on opinion and reasonable belief. Thus, a finding of probable cause does not require an inquiry into whether there is sufficient evidence to procure a conviction. It is enough that it is believed that the act or omission complained of constitutes the offense charged. Precisely, there is a trial for the reception of evidence of the prosecution in support of the charge. (Emphasis supplied)
The undersigned Prosecutor accuses ANDREW L. TAN @ CHONG BUAN, KATHERINE TAN, GERARDO GARCIA, CIRILO L. MANLANGIT, GEORGE T. YANG, THOMAS J. BARRACK, JR., ENRIQUE SANTOS L. SY, ROBERT J. ZULKOSHI [sic], ROBERTO S. GUEVARRA, ANTONIO T. TAN, ROSE A. CAMBALIZA, LOURDES G. CLEMENTE, NOLI HERNANDEZ, FRANCIS CANUTO, CIELO CUSTODIO, GUNTER RAMETSTEINER, CHARLES Y. UY, RAQUEL BONCAN and RICHMOND TAN of the crime of Violation of Section 5 of P.D. 957, committed as follows:
That on or about the 22nd day of November, 2000, in the City of Makati, Philippines and within the jurisdiction of this Honorable Court, the above-named accused, being then the responsible officers of Megaworld Corporation and Sedeño Manor, Inc. and in charge of the business of said corporation sold to complainant JULIETA E. BERNARDO a condominium unit described as 23E Tower II for the amount of Three Million Ninety Thousand and Three Hundred Pesos (P3,090,300.00), that while complainant was paying the monthly amortization due on the said condominium, accused conspiring and confederating together and mutually helping and aiding one another, did then and there willfully, unlawfully and feloniously failed to secure a Certification of Registration and License to Sell from the Housing and Land Use Regulatory Board (HLURB), in violation of the aforecited law. (Emphasis supplied)
SECTION 5. License to sell. - Such owner or dealer to whom has been issued a registration certificate shall not, however, be authorized to sell any subdivision lot or condominium unit in the registered project unless he shall have first obtained a license to sell the project within two weeks from the registration of such project.
The Authority, upon proper application therefore, shall issue to such owner or dealer of a registered project a license to sell the project if, after an examination of the registration statement filed by said owner or dealer and all the pertinent documents attached thereto, he is convinced that the owner or dealer is of good repute, that his business is financially stable, and that the proposed sale of the subdivision lots or condominium units to the public would not be fraudulent.
SECTION 2. Definition of Terms - When used in this Decree, the following terms shall, unless the context otherwise indicates, have the following respective meanings:x x x x x x x x x b) Sale or sell. – “Sale” or “sell” shall include every disposition, or attempt to dispose, for a valuable consideration, of a subdivision lot, including the building and other improvements thereof, if any, in a subdivision project or a condominium unit in a condominium project. “Sale” and “sell” shall also include a contract to sell, a contract of purchase and sale, an exchange, an attempt to sell, an option of sale or purchase, a solicitation of a sale, or an offer to sell, directly or by an agent, or by a circular, letter, advertisement or otherwise.
c) Buy and purchase. - The “buy” and “purchase” shall include any contract to buy, purchase, or otherwise acquire for a valuable consideration a subdivision lot, including the building and other improvements, if any, in a subdivision project or a condominium unit in a condominium project.x x x x x x x x x
SECTION 39. Penalties. -Any person who shall violate any of the provisions of this Decree and/or any rule or regulation that may be issued pursuant to this Decree shall, upon conviction, be punished by a fine of not more than twenty thousand (P20,000.00) pesos and/or imprisonment of not more than ten years: Provided, That in the case of corporations, partnership, cooperatives, or associations, the President, Manager or Administrator or the person who has charge of the administration of the business shall be criminally responsible for any violation of this Decree and/or the rules and regulations promulgated pursuant thereto. (Emphasis supplied)
Gentlemen :
I hereby tender my offer to purchase
UNIT NUMBERS: 23 E (STUDIO), TOWER II AREA: 37 sq.m.________________ CONTRACT PRICE: P3,090,300.00___________ LESS 5%: 2,935,785.00____________
under the following terms of payment:
DOWNPAYMENT : P NR-NDP______________ (30 days from date of Reservation) MONTHLY AMORTIZATION : P 19,571.90______________ in 60 months : ________________________ at 0% interest .p.a : ________________________ BALANCE UPON TURN-OVER50% : 1,467,892.50_____________
of your proposed PASEO PARKVIEW TOWER II Project to be constructed at the property located at THE CORNER STREETS OF VALERO, SAN AGUSTIN & SEDENO IN SALCEDO VILLAGE, MAKATI
In faith of my interest to purchase said unit/s; please find my reservation deposit, to wit:Cross Check No. __6291516__________________
dated __Nov. 22, 2000_______________________
in the amount of __P19,571.90__ , drawn against the FAR EAST BANK AND TRUST COMPANY ORTIGAS AVE., GREENHILLS Branch, payable to MEGAWORLD CORPORATION.
This amount shall form part of the downpayment.
I understand that you reserve the right to accept or deny this request for reservation. In the event of your acceptance hereof, and upon my full downpayment hereinabove-stated together with my delivery of the postdated checks to cover the balance of the purchase price, I agree to execute your standard Contract to Buy and Sell a copy thereof I have read, understood and agree to.
Should I fail to pay the downpayment and/or perform and execute any of the above conditions within the period stated, for any reason whatsoever, the reservation made will automatically be cancelled and the reservation fee and all my other payments shall be forfeited in your favor.x x x x x x x x x
RECEIPT
Received the amount NINETEEN THOUSAND FIVE HUNDRED SEVENTY ONE & 90/100 (P19,571.90) covered by FAR EAST BANK Check No. 6291516 dated Nov. 22, 2000 representing reservation deposit Unit/s 23 E of PASEO PARKVIEW TOWER 2. (Emphasis supplied)
The undersigned Prosecutor accuses ANDREW L. TAN @ CHONG BUAN, KATHERINE TAN, GERARDO GARCIA, CIRILO L. MANLANGIT, GEORGE T. YANG, THOMAS J. BARRACK, JR., ENRIQUE SANTOS L. SY, ROBERT J. ZULKOSHI [sic], ROBERTO S. GUEVARRA, ANTONIO T. TAN, ROSE A. CAMBALIZA, LOURDES G. CLEMENTE, NOLI HERNANDEZ, FRANCIS CANUTO, CIELO CUSTODIO, GUNTER RAMETSTEINER, CHARLES Y. UY, RAQUEL BONCAN and RICHMOND TAN of the crime of Violation of Section 20 of P.D. 957, committed as follows:
That on or about the 22nd day of November, 2000, in the City of Makati, Philippines and within the jurisdiction of this Honorable Court, the above-named accused, being then the responsible officers of Megaworld Corporation and Sedeño Manor, Inc. and in charge of the business of said corporation sold to complainant JULIETA E. BERNARDO a condominium unit described as 23E Tower II for the amount of Three Million Ninety Thousand and Three Hundred Pesos (P3,090,300.00), that while complainant was paying the monthly amortization due on the said condominium, accused conspiring and confederating together and mutually helping and aiding one another, did then and there willfully, unlawfully and feloniously failed to complete the project by December 2003, the deadline given by the Housing and Land Use Regulatory Board (HLURB), in violation of the aforecited law. (Emphasis supplied)
SECTION 20. Time of Completion. - Every owner or developer shall construct and provide the facilities, improvements, infrastructures and other forms of development, including water supply and lighting facilities, which are offered and indicated in the approved subdivision or condominium plans, brochures, prospectus, printed matters, letters or in any form of advertisement, within one year from the date of the issuance of the license for the subdivision or condominium project or such other period of time as may be fixed by the Authority.
Section 21. Time for Completion
Every owner or developer shall construct and provide the facilities, infrastructures, other forms of development, including water supply and lighting facilities and as far as practicable improvements, which are offered and indicated in the approved subdivision or condominium plans, brochures, prospectus, printed matters, letters or in any form of advertisement, within one ( 1) year or within such other period of time as may be fixed by the Board from the date of the issuance of license to sell for the subdivision or condominium project.
Request for extension of time to complete development of a subdivision or condominium project may be granted only in cases where non-completion of project is caused by fortuitous events, legal orders or such other reasons that the board may deem fit/proper with the written notice to lot or unit buyers without prejudice to the exercise of their rights pursuant to Section 23 of the Decree.
The request for extension of time for completion shall be accompanied by a revised work program duly signed and sealed by a licensed engineer or architect with project costing and financing scheme therefor. In appropriate cases, the Board may require the posting of additional performance bond amounting to 20% of development cost of the unfinished portion of the approved development plan, or issue such orders it may deem proper. (Emphasis supplied)
The undersigned Prosecutor accuses ANDREW L. TAN @ CHONG BUAN, KATHERINE TAN, GERARDO GARCIA, CIRILO L. MANLANGIT, GEORGE T. YANG, THOMAS J. BARRACK, JR., ENRIQUE SANTOS L. SY, ROBERT J. ZULKOSHI [sic], ROBERTO S. GUEVARRA, ANTONIO T. TAN, ROSE A. CAMBALIZA, LOURDES G. CLEMENTE, NOLI HERNANDEZ, FRANCIS CANUTO, CIELO CUSTODIO, GUNTER RAMETSTEINER, CHARLES Y. UY, RAQUEL BONCAN and RICHMOND TAN of the crime of Violation of Section 17 of P.D. 957, committed as follows:
That on or about the 22nd day of November, 2000, in the City of Makati, Philippines and within the jurisdiction of this Honorable Court, the above-named accused, being then the responsible officers of Megaworld Corporation and Sedeño Manor, Inc. and in charge of the business of said corporation sold to complainant JULIETA E. BERNARDO a condominium unit described as 23E Tower II for the amount of Three Million Ninety Thousand and Three Hundred Pesos (P3,090,300.00), that while complainant was paying the monthly amortization due on the said condominium, accused conspiring and confederating together and mutually helping and aiding one another, did then and there willfully, unlawfully and feloniously failed to register the reservation agreement in the Office of the Register of Deeds of Makati City, in violation of the aforecited law. (Emphasis supplied)
SECTION 17. Registration. -All contracts to sell, deeds of sale and other similar instruments relative to the sale or conveyance of the subdivision lots and condominium units, whether or not the purchase price is paid in full, shall be registered by the seller in the Office of the Register of Deeds of the province or city where the property is situated. x x x. (Emphasis supplied)