433 Phil. 79
AUSTRIA-MARTINEZ, J.:
“IN THE LIGHT OF ALL THE FOREGOING, the Decision appealed from is AFFIRMED with the following modifications:Petitioner Bataan Seedling Association, Inc. (BSAI for brevity) entered into a Community Based Reforestation Contract on October 26, 1990 with the Republic of the Philippines, represented by the Department of Environment and Natural Resources (DENR). Under said contract, BSAI, in consideration of the amount of Nine Hundred Seventy Five Thousand One Hundred Twenty Six Pesos and Sixty One Centavos (P975,126.61), bound itself to undertake the reforestation of a fifty-hectare open/denuded forest land in Barangay Liyang, Pilar, Bataan within a period of three (3) years.[3] BSAI likewise undertook to report to the DENR any event or condition which delays or may delay or prevent completion of the work,[4] and submit progress billings and accomplishment reports.[5] Concomitant with the contract is the Project Development Plan and the Approved Schedule of Progress Payments detailing the annual cash flow and schedule of activities within the three-year period,[6] and the Contract of Undertaking providing for the mobilization fund in the amount of Seventy Five Thousand Fifty Four Pesos and Sixty Six Centavos (P75,054.66).[7] Said fund was allotted and released by respondent to enable BSAI to start with the project, but the fund was to be returned to respondent upon completion of the project or deducted from the periodic release of moneys to petitioners.[8]
- The Appellants are hereby ordered to pay, jointly and severally, to the Republic of the Philippines, the principal amount of P56,290.69, with interest thereon at the rate of 12% per annum, from January 27, 1994 until the said amount is paid in full;
- The Appellant BSAI is hereby ordered to pay to the appellant Republic of the Philippines the amount of P50,000.00 as and by way of exemplary damages.
No pronouncement as to cost.
SO ORDERED.”[2]
“1. Willful violation of the material terms and conditions, stipulations and covenants of the Contract, to wit: a) The association failed to fully plant/establish the whole 50-hectare contracted area during the first year of operations as provided for in the Contract; b) The seedlings raised in the nursery were disposed of to other contractors and the seedlings left were practically overgrown indicating lack of proper care and maintenance; c) Inspite of the fact that a forest fire occurred sometime in December, 1991, no report was ever made to the DENR in violation of Article 1.1.5 of the Contract; d) The Association even failed to submit to the DENR accomplishment reports and other relevant information required and expected from it.Due to their failure to respond to the notice of cancellation, as well as return the mobilization fund, respondent filed a Complaint for Damages against petitioners,[10] praying that the latter jointly and solidarily pay actual damages in the amount of Seventy Five Thousand Fifty Four Pesos and Twenty Five Centavos (P75,054.25) representing the portion of the mobilization fund released to them, and Sixty Two Thousand Pesos Four Hundred Fifty Pesos and Twenty Two Centavos (P62,450.22) as the amount paid under the accomplishment bills, totaling One Hundred Thirty Seven Thousand Five Hundred Four Pesos and Forty Seven Centavos (P137,504.47). Respondent also sought liquidated damages equivalent to 0.1% of the total contract cost due to BSAI’s delay in the performance of its obligations, and exemplary damages in the amount of Fifty Thousand Pesos (P50,000.00).[11]
“2. Abandonment of the project area. The PENRO/CENRO monitoring and Evaluation Team which inspected the project area on March 18, 25 and 31, 1992 reported that except for the family that actually resides in the bunkhouse, no laborers were observed at the project area during the time of the field inspections. Even you failed to show up despite written and verbal notices served to you. Finally, the photodocuments taken on the plantation illustrates clearly the abandoned project area.”[9]
At the outset, it must be stated that the foregoing issues and the respective arguments in support thereof have been raised by the parties and passed upon by both the trial court and the appellate court.
“1. Whether the unilateral cancellation by the respondent of the Community-Based Reforestation Contract is invalid, being without factual and legal basis.“2. Whether the order to refund the amount of P56,290.69 with interest at the rate of 12% per annum, representing the balance of the mobilization fund, is palpably erroneous as being contrary to the facts.” [15]
“x x x The Appellant BSAI unabashedly admitted failing to establish/plant the project area. Under Section 1.1.5 of the Contract, the Appellant BSAI was obliged to report to the DENR any event or condition which delayed or may delay the progress or prevent the completion, of the work under the time-table set forth under the contract or any relevant facts known to the Appellant BSAI. A fire in the area which gutted the improvements in contract area occurred in December, 1991. However, the Appellant BSAI never informed the DENR of said fire. Worse, the Appellant BSAI did not anymore conduct any replanting activities on the area, thus accounting, in part, for the failure of the said Appellant to submit periodic progress reports on its activities in said area. Even before the fire occurred, in December 1991, the Appellant BSAI already failed to submit any periodic reports of progress of its activities in the area. This prompted the DENR to conduct an on the site inspection of the subject project area. Indeed, Carlos Valencia and Hernani Salaya Jr., even ignored the requests of DENR for them to be present during the said inspections. The DENR inspection team found and discovered that the Appellant BSAI failed to fully establish planting on the subject project area. Instead of planting the seedlings on the project area, the Appellant BSAI sold some of the seedlings because of its failure to pay the nursery owner, Anilao Satellite Nursery, located in Pilar, Bataan for said seedlings. x x x”[21]Petitioners attempt to trivialize their lapse, but the Court believes that this is not merely a slight or casual breach, but a substantial one giving sanction to the cancellation. Under Clause 4.1 of the contract, respondents “shall have the right to suspend, terminate or cancel” the contract upon petitioners’ substantial failure to fulfill their obligations, or a willful violation of the material conditions, stipulations and covenants thereof. It can be concluded from the tenor of said clause that the parties intended mandatory compliance with all the provisions of the contract. As stated previously, among such provisions requiring strict adherence are the submission of progress reports and the reporting of such event which may delay or prevent the project. Hence, upon petitioners’ failure to comply with said obligations, respondent was well within its right to cancel the contract by express grant of Clause 4.1.
“THAT BATAAN SEEDLING ASSOCIATION, INCORPORATED x x x, for and in consideration of the sum of Seventy Five Thousand Fifty four pesos and sixty six centavos (P75,054.66) representing advance payment under said contract receipt of which is hereby acknowledge in full, as hereby bind ourselves;The amount of Seventy Five Thousand Fifty Four Pesos and Sixty Six Centavos (P75,054.66) advanced to BSAI, represents 15% of Five Hundred Thousand Three Hundred Sixty One Pesos and Seventy Two Centavos (P500,361.72), the contract cost for the 1st year.[23] When initial payment was made by respondent to petitioners on February 25, 1991, the amount of Eighteen Thousand Seven Hundred Sixty Three Pesos and Fifty Six Centavos (P18,763.56), or 1/4 of the mobilization fund, was deducted,[24] leaving a balance of Fifty Six Thousand Two Hundred Ninety Pesos and Sixty Nine Centavos (P56,290.69). Respondent thereafter made no deductions on the subsequent payments of the contract price remitted to petitioners. Hence, they remain liable on the balance of said fund in the amount of Fifty Six Thousand Two Hundred Ninety Pesos and Sixty Nine Centavos (P56,290.69). We find no error committed by the Appellate Court on this matter.x x x
3. To repay the amount advanced in accordance with the Contract of Reforestation and DENR Administration order No. 14 Series of 1989 as amended;”[22] (Emphasis Ours)
“I. When an obligation, regardless of its source, i.e., law, contracts, quasi-contracts, delicts or quasi-delicts is breached, the contravenor can be held liable for damages. The provisions under Title XVIII on ‘Damages’ of the Civil Code govern in determining the measure of recoverable damages.Interest at the rate of 12% per annum is imposable if there is no stipulation in the contract. Herein subject contract does not contain any stipulation as to interest. However, the amount that is due the respondent does not represent a loan or forbearance of money. The word “forbearance” is defined, within the context of usury law, as a contractual obligation of lender or creditor to refrain, during given period of time, from requiring borrower or debtor to repay loan or debt then due and payable.[26] The contract between petitioner and respondent is a Community Based Reforestation Contract by virtue of which petitioner undertook the reforestation of a fifty-hectare open/denuded forest land. The amount of Fifty Six Thousand Two Hundred Ninety Pesos and Sixty Nine Centavos (P56,290.69) due to respondent, represents the balance of the mobilization fund which petitioner is obliged to return because of its failure to fully comply with its undertaking to plant the entire area with seedlings within the period contracted for reforestation. Under the reforestation contract, the fund released to petitioner was supposed to be returned to respondent upon completion of the project or deducted from the periodic releases of money. Clearly therefrom, the amount of Fifty Six Thousand Two Hundred Ninety Pesos and Sixty Nine Centavos (P56,290.69) was neither a loan nor forbearance of money.
“II. With regard particularly to an award of interest in the concept of actual and compensatory damages, the rate of interest, as well as the accrual thereof, is imposed, as follows:“1. When the obligation is breached, and it consists in the payment of a sum of money, i.e., a loan or forbearance of money, the interest due should be that which may have been stipulated in writing. Furthermore, the interest due shall itself earn legal interest from the time it is judicially demanded. In the absence of stipulation, the rate of interest shall be 12% per annum to be computed from default, i.e., from judicial or extrajudicial demand under and subject to the provisions of Article 1169 of the Civil Code.
“2. When an obligation, not constituting a loan or forbearance of money, is breached, an interest on the amount of damages awarded may be imposed at the discretion of the court at the rate of 6% per annum. No interest, however, shall be adjudged on unliquidated claims or damages except when or until the demand can be established with reasonable certainty. Accordingly, where the demand is established with reasonable certainty, the interest shall begin to run from the time the claim is made judicially or extrajudicially (Art. 1169, Civil Code) but when such certainty cannot be so reasonably established at the time the demand is made, the interest shall begin to run only from the date the judgment of the court is made (at which time the quantification of damages may be deemed to have been reasonably ascertained). The actual base for the computation of legal interest shall, in any case, be on the amount finally adjudged.
“3. When the judgment of the court awarding a sum of money becomes final and executory, the rate of legal interest, whether the case falls under paragraph 1 or paragraph 2, above, shall be 12% per annum from such finality until its satisfaction, this interim period being deemed to be by then an equivalent to a forbearance of credit.” [25]
1) | The interest to be paid on the amount of Fifty Six Thousand Two Hundred Ninety Pesos and Sixty Nine Centavos (P56,290.69) shall be at the rate of 6% per annum from the Court of Appeals Decision dated October 14, 1998. A twelve percent (12% ) interest, in lieu of six percent (6%) shall be imposed upon finality of this decision, until full payment thereof. | |
2) | The award of exemplary damages is reduced from Fifty Thousand Pesos (P50,000.00) to Twenty Thousand Pesos (P20,000.00). |